Agenda

Back to Calendar Return

AI- 53405

Commissioners Court

Meeting Date:	01/09/2023
FYI Change Order No. 2 to Acumen Enterprises Inc.
Submitted For:	Bill Burke	Submitted By:	Lisa Bunch
Department:	Construction Projects
Request Type:	FYI	Agenda Area:	Miscellaneous

Information

Department Action

FYI to Commissioners’ Court for Change Order No. 2 to Acumen Enterprises Inc., for IFB 2022-198, Repairs to Second Floor Walkway and First Floor Soffit, 900 E. Park Blvd., Plano, TX.
Contractor requested to add twenty-three calendar days to completion date for weather delays. Previous completion date: 1/14/23. New completion date: 2/7/23.
Total for this change order - $0.00.
Total changes for this contract - $13,514.00 or 1.80% of contract.

Purchasing Department Action

FYI notification to Commissioners Court of Contract Change Order No. 2 to Acumen Enterprises, Inc. for IFB
2022-198, Construction, Exterior Repairs to Second Floor Walkway & First Floor Soffit, 900E. Park Blvd., Plano
per the attached documents. jdg

HR and/or IT Action

Budget Department Action

Change Order No. 2 to IFB 2022-198, Repairs to Second Floor Walkway and First Floor Soffit, 900 E. Park Blvd., Plano, TX with Acumen Enterprises Inc. to extend the contract completion date to February 7, 2023. No action by Budget.

Auditor's Office Action

No action by Auditor.

Commissioners Court

Change Order No. 2 to Construction, Exterior Repairs to Second Floor Walkway & First Floor Soffit, 900 E. Park Blvd., Plano to add twenty-three (23) calendar days to completion date for weather delays, Construction & Projects.

Budget Information

Information about available funds

Budgeted:

Funds Available:

Adjustment:

Amount Available:

Unbudgeted:

Funds NOT Available:

Amendment:

Account Code(s) for Available Funds
1:

Fund Transfers

Remarks:

NO FISCAL IMPACT. LB

Attachments
Memo
Change Order 2
Change Order Request