Agenda

Back to Calendar Return

AI- 50433

Commissioners Court

Meeting Date:	06/21/2021
Change Order No. 2 to Construction, New Office Building for Precinct 2, M-PAK Construction
Submitted For:	Bill Burke	Submitted By:	Lisa Bunch
Department:	Construction Projects
Request Type:	FYI	Agenda Area:	Miscellaneous

Information

Department Action

FYI to Commissioners’ Court for Change Order No. 2 to M-PAK Construction for Construction, New Office Building for Precinct 2 Justice of the Peace and Constable. PCO 4 – Contractor request substitution of 12” of rock full height of retaining wall for prefabricated sheet drain. $2.94
Contractor request fifty-five (55) additional weather delay days due to rain. Original project completion date: June 8, 2021. New project completion date: August 2, 2021.
Total for this Change Order – $2.94 or 0.00000133% of contract
Total Change Orders for the Project – $3,621.94 or 0.016% of contract

Purchasing Department Action

FYI notification to Commissioners Court of Contract Change Order No. 2 to M-Pak Construction, Inc. for Construction, New Office Building for Precinct 2 Justice of the Peace & Constable, IFB 2020-272 per the attached documents. jdg

HR and/or IT Action

Budget Department Action

Budgeted funds available in the amount of $2.94 for Change Order No. 2 to IFB 2020-272 with M-Pak Construction, Inc for Contractor requested substitution and extend the project completion date to August 2, 2021. New contract total is $2,218,621.94. 2018 Tax Notes (4406).

Auditor's Office Action

Tax Note funds available.

Commissioners Court

Change Order No. 2 to Construction, New Office Building for Precinct 2, Justice of the Peace & Constable (IFB No. 2020-272) with M-Pak Construction, Inc. to provide changes to the contract, Construction Projects.

Budget Information

Information about available funds

Budgeted:

Funds Available:

Adjustment:

Amount Available:

$2.94

Unbudgeted:

Funds NOT Available:

Amendment:

Account Code(s) for Available Funds
1:	FI18LAVNCH-4406-400308043-809110

Fund Transfers

Remarks:

Attachments
Memo
Change Order Request
Contract Change Order 2